The High Court of Delhi has held that mere recommendation by Independent Engineer (IE) for Extension of Time (EOT) to the contractor does not necessarily mean the NHAI was responsible for the delays in the completion of the project work. The division bench of Justices Vibhu Bakhru and Amit Mahajan held that when the agreement between the parties provides for compensation and…
